Search

Displaying 1 - 4 of 4

Lesson
The need for proper arrangements to meet customary ceremony requirements, which can cause delays, should be anticipated in future project designs. For example, because a sacred cemetery to the community was identified at the construction site of a project package, a customary ceremony was needed and conducted to meet the local community's religious requirements.

Project Number: 41074-013
Project Name: West Kalimantan Power Grid Strengthening Project
Report Date:
Lesson
A draft proposal on income restoration and rehabilitation programs need to be prepared along with the safeguard plans to avoid delays in safeguards implementation. In this project, contractors of four packages should have deployed fulltime environmental and occupational safety and health personnel to raise awareness and enforce the safeguard requirements for subcontractors and workers.

Project Number: 41074-013
Project Name: West Kalimantan Power Grid Strengthening Project
Report Date:
Lesson
Adequate due diligence and consultation with government agencies and related stakeholders throughout the project cycle will help ensure appropriate project planning, preparation, design, and implementation and avoid unnecessary scope changes that reduce the overall process efficiency.

Project Number: 42414-033
Project Name: Sustainable Urban Transport Investment Program (Tranche 2)
Report Date:
Lesson
Independent technical studies are useful in addressing project-related grievances. The executing agency, in collaboration with ADB, determined that specific studies, including noise and vibration studies, had to be completed before proposing solutions to address the concerns of the complainants. While the proposed RAP was not accepted by the complainants, the technical studies proved useful in establishing the deficiencies of the IEE and could be built upon in addressing issues of similar nature.

Project Number: 42414-043
Project Name: Sustainable Urban Transport Investment Program - Tranche 3
Report Date: